Terms and Conditions
Our state-of-the-art system includes:
Front and back doors protected
Infrared interior motion detector
Digital keypad with police, fire, and medical emergency buttons
Interior siren
Control panel with battery back-up
Lawn sign and window decals
Your home security system is monitored by ADT professionals 24 hours a day, 7 days a week.
It is expressly understood and agreed that all sales shall be subject to the following items and conditions and those contained on the face hereof:
1. ENTIRE AGREEMENT:
This instrument contains all the terms and conditions with
respect to the sale and purchase of the material or
merchandise described hereof, and supersedes any and
all other instruments or agreements, and no change
or modification of these terms and conditions shall
be of any force unless such change or modification
shall be executed by an authorized officer of Protect Your Home.
The terms and conditions as set forth in this instant
instrument shall supersede any provision, terms and
conditions contained on any purchase order, confirmation
order or other writing that Buyer may give or have
received, and the rights of the parties shall be governed
exclusively by the provisions, terms and conditions
hereof. Protect Your Home makes no representations or warranties
concerning this confirmation except such as are expressly
contained herein and this confirmation may not be changed
or modified orally.
2. WARRANTIES AND LIABILITIES OF Protect Your Home:
EXCEPT AS HEREIN SET FORTH, Protect Your Home MAKES NO WARRANTIES OR REPRESENTATIONS, EXPRESSED
OR IMPLIED, WITH RESPECT TO THE MERCHANDISE, AND THE BUYER HEREBY EXPRESSLY
WAIVES ALL SUCH WARRANTIES, GUARANTEES AND REPRESENTATIONS INCLUDING ANY IMPLIED
WARRANTY OF MERCHANTABLITY OR FITNESS FOR A PARTICULAR PURPOSE. Protect Your Home SHALL,
IN NO EVENT, BE LIABLE FOR ANY CONSEQUENTIAL OR INCIDENTAL DAMAGES SUSTAINED
BY BUYER ARISING OUT OF THIS TRANSACTION.
3. LIABILITY:
Protect Your Home shall not be liable for loss or damage of any kind
resulting from delay or inability to deliver, or failure
to deliver caused directly or indirectly by acts of God
or the public enemy, riots, accident, strikes or differences
with labor, labor shortage, inability to obtain material
or equipment, or transportation or fuel, explosions, epidemics,
quarantine, restrictions, unusually severe weather, compliance
with or the operation of any applicable governmental legislation,
regulation, directive or order of any government or of
the United States or of any state or other political subdivision
thereof, judgments or order of any court of competent jurisdiction,
order or rulings of any board, agency, commission, officer
or other competent governmental authority, of any government
of the United States or of any state or other political
subdivision thereof, or any other thing beyond Protect Your Home’s
absolute and unconditional control: Protect Your Home shall not be
required to use overtime labor, nor to expend any monies
whatsoever to cure any such delay or failure to deliver.
In the event of such delay, the date of delivery of this
order shall be extended by a period of time approximately
equal to the time lost by reason of the delays. In the
event of any partial failure to deliver so caused, Protect Your Home
shall have the right to prorate payment for such of the
merchandise as it could and did in fact deliver, whether
or not delivery of the same may have been delayed.
4. CLERICAL AND STENOGRAPHICAL ERRORS:
Obvious Quotation or Purchase Order clerical and stenographic error(s) of Protect Your Home
or Buyer shall be subject to correction, after notification thereof of such
error(s), and both parties hereto agree to such corrections. While information
contained herein is deemed to be accurate, we cannot be made responsible for
errors and/or omissions. Protect Your Home promotions may and do change often and cannot,
under any circumstance be made retroactive. As an authorized retailer of US
Alarm's programming packages and promotions, we hereby represent that we have
no control over promotions and/or pricing of Protect Your Home products and that US
Alarm shall be the sole determining party as to any consumer entitlements under
a Protect Your Home promotion.
5. EARLY TERMINATION OF SERVICE FEE:
PLEASE NOTE: IN THE EVENT THAT YOU SEE FIT TO DISPUTE ANY
CHARGES MADE TO YOUR CREDIT CARD, PLEASE CONTACT US SO THAT WE MAY PROPERLY AND SATIFACTORILY SATISFY THE
DISPUTE, PRIOR TO DISPUTING ANY CHARGE DIRECTLY WITH
YOUR CREDIT CARD COMPANY AND/OR FINANCIAL INSTITUTION.
IN THE EVENT THAT A REFUND REQUEST HAS BEEN GRANTED AND
IT IS LATER DETERMINED THAT AN Protect Your Home SECURITY SYSTEM
INSTALLATION HAS TAKEN PLACE IN YOUR HOME, WE DO RESERVE
THE RIGHT TO RE-CHARGE YOUR CARD THE PREVIOUSLY REFUNDED
ACTIVATION FEE.
6. APPLICABLE LAW:
The entire Transaction shall be governed by the applicable
provisions of the Uniform Commercial Code of the State of California;
Protect Your Home accepts Buyer's order only upon the condition that
Buyer assents to all of the terms and conditions contained
herein. All such terms and conditions shall be deemed accepted
by Buyer if:
a. Buyer does not object in writing thereto within the time provided by this paragraph; or
b. Buyer accepts, uses or exercises control over the goods which are the subject of the contract. Any objection by Buyer to any of the terms or conditions hereof shall be effective only if received by Protect Your Home at its main office in Anaheim, Orange County, California prior to the first occurrence of the following:1. the creation and acceptance of a Protect Your Home installation appointment.
2. the completion of installation appointment and activation of Protect Your Home satellite TV equipment.
7. DISCLOSURE:
Protect Your Home.com, LLC (“Protect Your Home”) is an Authorized Retailer for Protect Your Home,
Inc. (“Protect Your Home”). By placing your order by phone or via the Internet
with Protect Your Home, you are agreeing to the following terms and conditions governing
your purchase of merchandise, and/or services from Protect Your Home. It is understood
that Protect Your Home is not ADT but is an authorized ADT dealer/reseller. All installations
are performed by Protect Your Home and its subcontractors.
BY ORDERING FROM PROTECT YOUR HOME, I HEREBY ACKNOWLEDGE THAT I HAVE READ THE ABOVE TERMS AND CONDITIONS, UNDERSTAND THEM, AND AGREE TO BE LEGALLY BOUND BY THEM.
